All projects are entered onto schedule after receipt of cleared payment. Start Date refers to estimated date that we will begin your project. Although every effort is made to meet or exceed estimated completion dates, estimated timelines represent our best estimate only, and in no way indicate a guaranteed timeframe for completion. Tulsa Marketing shall not be liable for any losses or damages (including consequential or incidental damages) which result from delay or failure to complete projects on or before estimated completion dates. Timeline is subject to change based on projects that may have recently entered the schedule. Client to provide requested information in a timely manner to maintain project start and completion dates.
Client acknowledges services includes the exclusive access to prospective client leads, sales, donations, limited wordpress backend, hosting provided for the website or landing page, domain name provided, SEO services for the website, Google analytics reports, Phone call reports and keyword ranking reports. Tulsa Marketing endeavors to fulfill obligations set out in the services provided section and will use various marketing techniques. Tulsa Marketing uses proprietary digital marketing techniques learned over 14+ years to enhance websites on search engines and website delvopment.
Client also acknowledges that any payment of services is an acknowledgment of services received. Because of this, no refunds are issued. Client also acknowledges the services from Tulsa Marketing including but not limited to SEO, Web Design, Graphics Design, Email Marketing, Autoresponders, Optin Plugins, Lead Capture Code or Pages, Landing Pages, Squeeze Pages, PPC, CPM, Adwords, CPA, Pay for Traffic, Search Engine Marketing, Social Media Marketing, Business Consultation, In Bound Marketing, Analytics, Traffic Funnels, and Lead Generation are not tangible physical products but are intangible.
Client agrees to pay for any damage he/she might cause to the marketing campaign/landing page/website or Tulsa Marketing and promises to reimburse any and all fees and costs resulting from repair of the marketing campaign/landing page/website or legal proceedings based upon this agreement.
Mediation: Client agrees that in the result of a dispute or claim against Tulsa Marketing client will attend and comply with mediation proceedings by Jeff Burritt in Tulsa County Oklahoma or Tulsa Marketing’s appointed mediator. Any and all disputed issues will be resolved and consider binding, with limited rights or appeal by the mediator. The prevailing party shall be reimbursed by the other party for any and all costs associated with the dispute including mediation or arbitration, attorney fees, collection fees, investigation fees and travel expenses.